Doc. issued 4th March 2019
Quoted shipping schedule is based on current shop load and is subject to change at time of purchase or release. Please confirm at time of order.
NOTWITHSTANDING ANYTHING TO THE CONTRARY AND AS PERMITTED TO THE FULLEST EXTENT OF LAWS AND REGULATIONS, COMPANY IS NOT LIABLE TO CUSTOMER OR ANY THIRD PARTY FOR INDIRECT, CONSEQUENTIAL, SPECIAL, PUNITIVE, INCIDENTAL DAMAGES OR LOST PROFITS ARISING UNDER ANY SALE OF GOODS OR SERVICES UNDER THESE TERMS AND CONDITIONS.
Given the pending change on tariffs introduces an unpredictable element to our raw material cost structure and could adversely impact this quote, all new orders must be reviewed prior to acceptance. As we have always done, we will be close to this market and look for the absolute best cost position to enable us to continue to meet your quality standards. Please expedite decision so that we can proactively procure raw materials that might be impacted by tariffs.
1) Scope. Prices quoted are valid for thirty (30) days from date of quotation unless otherwise stated. The terms and conditions of sale set forth below apply to all quotations made and purchase orders accepted by Facet, Jonell, Filtration Group Process or other Process Technologies entity referenced in the quote (“Seller”). To the extent there is any conflict between the terms included in the quote by Seller and these terms and conditions, these terms and conditions shall control unless otherwise indicated in this agreement. Price and other commitments contained in the quote are based upon information known by Seller at the time the quote is issued. Prices and terms are subject to change based on new information learned or provided after the date of the quote, including but not limited to the application of any new tariff, unforeseen change in raw material pricing, or cost increase caused by international monetary fluctuations on import.
2) Acceptance of Orders. All orders are subject to acceptance by authorized officials at Seller’s division or subsidiary offices.
3) Scheduling. Shipping dates are approximate and are based upon prompt receipt of all necessary information. Buyer shall furnish to Seller written shipping instructions in sufficient time to permit Seller to make shipment at Seller’s option within any time or times herein specified for shipment. In the event of a delay in delivery due to any reason described In Section 16 below, the delivery date shall be deferred for a period equal to the time lost by reason of delay. In the event such delay shall continue for more than two weeks then, at Seller’s option, the order will be deemed cancelled without liability to Seller.
4) Delivery and Transportation. Seller’s delivery dates are approximate, and Seller shall use commercially reasonable efforts to deliver in accordance with the delivery and performance schedules. Seller shall not be liable for delays in delivery or other defaults in performance of this order arising out of causes beyond Seller’s control. In any case, time of delivery is not of the essence. Delivery of the products hereunder shall be made EXW Incoterms® 2010 Seller’s designated shipping point. Title and risk of loss to products passes to Buyer when Seller makes the products available to Buyer at the Seller designated shipping point. Transportation expenses will be paid by Buyer and risk of loss, shortage, delay or damage to products in transit shall fall upon Buyer, whose responsibility it shall be to file claims with the carrier. For large quantity commodity orders, seller reserves the right to a 10% excess or shortfall in deliveries.
4) Terms of Payment. Invoiced amounts may be adjusted by Seller based on foreign currency fluctuations when quote references FX rate used for goods to be imported. Invoices are due and payable (14) fourteen days from the date of invoice unless otherwise indicated in the invoice. A 1 1/2% per month carrying charge will be applied to all past due amounts or the maximum rate permitted by applicable law, whichever is higher. Buyer agrees to pay reasonable attorney fees, court cost, and other collection expenses which might be incurred in the collection of Buyer’s overdue account in the event of the failure of Buyer to timely pay any account owing by Buyer to Seller. If shipments are delayed by Buyer, payments shall become due on the date when Seller is prepared to make shipment and Buyer shall be responsible for a delay fee of 1% of the total order value plus any storage, handling, or other costs incurred by Seller. If the work covered by the purchase order is delayed by Buyer, payments shall be made based on the purchase price and the percentage of completion. Seller reserves the right to ship to its order and make collection by sight draft with bill of lading attached.
6) Taxes. Prices do not include foreign or domestic sales, use, excise or similar taxes. Consequently, in addition to the prices specified herein, the amount of any present or future sales, use, excise or other general or specific tax, or export or import duties, tariff or penalties or other governmental charges fixed or imposed by any lawful authority(s) upon or applicable to the production, sale, shipment, delivery or use of the products (or raw materials in the products) sold hereunder shall be added to the price and be paid by Buyer or, in lieu thereof, Buyer shall provide Seller with a tax exemption certificate acceptable to the taxing authorities. If such tax is paid by Seller, Buyer shall reimburse Seller upon presentation of invoice.
7) Warranty. Seller warrants the products manufactured by it shall meet the specifications accepted by Seller for the period set forth below. The extent of Seller’s obligation hereunder is to either repair or replace its nonconforming products at the location designated by Seller in its sole discretion, if Buyer notifies Seller of any non-conformance within eighteen (18) months after date of delivery or twelve (12) months from the day of first product use whichever comes first. No allowance will be granted for repairs or alterations made by Buyer without Seller’s written approval. The warranty shall not be construed to cover the cost of any work done by Buyer on material furnished by Seller or the cost of removal or installation of product. Products and parts not manufactured by Seller are warranted only to the extent and in the manner that the same are warranted to Seller by Seller’s vendors and then only to the extent Seller is able to enforce such warranty.
8) THE FOREGOING STATES THE SOLE AND EXCLUSIVE WARRANTIES PROVIDED BY SELLER TO BUYER AND THERE ARE NO OTHER WARRANTIES EITHER EXPRESSED OR IMPLIED IN FACT OR BY LAW. THE WARRANTIES STATED HEREIN ARE IN LIEU OF ALL OTHER WARRANTIES, WRITTEN OR VERBAL, STATUTORY, EXPRESSED OR IMPLIED, INCLUDING WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE, WHICH ARE HEREBY DISCLAIMED. SELLER’S WARRANTY DOES NOT APPLY TO ANY GOODS WHICH HAVE BEEN SUBJECTED TO MISUSE, MISHANDLING, MISAPPLICATION, NEGLECT, (INCLUDING BUT NOT LIMITED TO USE OF UNAUTHORIZED PARTS OR ATTACHMENTS), OR ADJUSTMENT OR REPAIR PERFORMED BY ANYONE OTHER THAN SELLER OR ONE OF SELLER’S AUTHORIZED AGENTS.
9) Limitation of Liability. Seller shall not be responsible, obligated, or liable for any injury or damage resulting from an application or use of its products, either singly or in combination with other products. SELLER’S SOLE LIABILITY FOR BREACH OF WARRANTY OR ANY OTHER CLAIM SHALL BE LIMITED TO REPAIR OR REPLACEMENT OF THE PRODUCTS OR RETURN OF THE PURCHASE PRICE, AT SELLER’S SOLE OPTION. SELLER SHALL NOT BE LIABLE FOR DAMAGES, INCLUDING BUT NOT LIMITED TO CONSEQUENTIAL, INCIDENTAL, PUNITIVE, LIQUIDATED OR SPECIAL DAMAGES ARISING OUT OF OR IN CONNECTION WITH THE USE OR PERFORMANCE OF THE PRODUCTS OR ARISING OUT OF ACCEPTANCE OF THIS ORDER. BUYER SHALL INDEMNIFY SELLER AGAINST ALL LIABILITY, COST, OR EXPENSE THAT MAY BE SUSTAINED BY SELLER BECAUSE OF ANY SUCH LOSS, DAMAGE, OR INJURY.
10) Acceptance of Products. Products will be deemed accepted without any claim by Buyer unless written notice of non- acceptance is received by Seller within fourteen (14) days of delivery. Such written notice shall not be considered received by Seller unless it is accompanied by all freight bills for such shipment, with agent’s notations as to damages, shortages and conditions of equipment, containers and seals. Non-accepted products are subject to return policy stated below.
11) Return of Products. No product may be returned to Seller without Seller’s prior written permission the form of a return material authorization.
12) Damages to Returned Products. If Buyer elects to return product(s) to Seller for refurbishment, Buyer agrees to accept all risk of damage or destruction of such returned product(s), and Seller shall not be liable for any failure or inability on the part of Seller to complete refurbishment upon any such returned products.
13) Limitations of Actions. All claims, demands or actions must be brought within one (1) year of date of tender of delivery, or eighteen (18) months of Buyer’s order, if no tender of delivery is made, notwithstanding any statutory period of limitation to the contrary.
14) Intellectual Property. Buyer shall defend, indemnify and hold Seller harmless against all claims, demands judgment, expense or loss resulting from infringement of third-party patents, copyrights or trademarks arising from Seller’s compliance with Buyer’s design, specifications or instructions. Seller retains all intellectual rights, title and interest in the products and its underlying technology, delivered hereunder including Seller’s process, manufacturing and all other technologies used in Seller’s performance hereunder. The sale of products or parts hereof by Seller does “not convey any license, rights, title or interest by implication, estoppel, or otherwise, under patent claims, industrial property right, trademark, trade secret or any other intellectual property rights covering combinations of these products or parts with other devices or elements. Buyer agrees that Seller may receive service and condition related data from the products for the purpose of providing support, services, and improving the products. Buyer may opt out of this collection of data by providing Seller with written notice. Seller may share such information with its distributors and service representatives for purposes of providing support to Buyer.
15) Financial Responsibility. If in the sole Judgment of Seller, the financial resources of Buyer become impaired or unsatisfactory at any time during the term of the agreement between the parties, then Seller may require of Buyer a deposit or suitable security or margin for performance by Buyer in such amount or amounts from time to time as Seller shall specify. Upon requirement of deposit, Buyer shall make such deposit not later than the close of Seller’s next business day. If Buyer falls to make such deposit, then Seller may at its option (1) cancel the agreement between the parties or the undelivered portion thereof. In which case Buyer agrees to pay Seller the difference between the market price on date of cancellation and the contract price; (2) resell at any time for Buyer’s account all or any undelivered portion of the products, in which case Buyer agrees to pay Seller the difference between the resale price and the contract price, or (3) otherwise change the terms of payment. In the event Buyer shall be or becomes insolvent, or admits in writing Buyer’s inability to pay Buyer’s debts as they mature, or if Buyer shall make an assignment with creditors or if there are instituted by or against Buyer proceedings in bankruptcy or under any insolvency laws or for reorganization, receivership or dissolution, Seller may terminate the agreement between the parties at any time and without notice.
16) Force Majeure Seller is excused for non-performance caused by any factor beyond its control Including but not limited to events of war, fire, epidemics, quarantine restrictions, flood, strike, labor trouble, breakage of equipment, accident, riot, the imposition of any government price control regulation or tariff, or any other act of governmental authority, acts of God or other contingencies (whether similar or dissimilar to the foregoing) beyond the reasonable control of Seller, interfering with the production, cost, supply, transportation, or consumption practice of Seller at the time respecting the products covered by the agreement between the parties or in the event of inability to obtain on terms deemed by Seller to be practicable any raw material (Including without limitation energy source) used in connection therewith, quantities so affected shall be deemed to be an excusable delay in Seller’s performance for the duration of time such condition exists. As promptly as practicable Seller will notify Buyer of any force majeure events that delays or threatens to delay Seller’s timely performance hereunder. Seller may during any period of shortage due to any of these causes, allocate its supply of such raw material among its various uses therefore (e.g. manufacturing and sales) in such manner as Seller deems practicable and allocate its supply of such products among such various uses thereof in any manner which Seller deems fair and reasonable.
17) Reasonable Attorney’s Fees. In the event suit or other proceeding shall be brought for the recovery of the purchase price, or any unpaid balance or the breach by Buyer of any term of the agreement between Seller and Buyer, Buyer shall pay to Seller in addition to any damages provided by law, reasonable attorney’s fees and costs of collection.
18) Security Title. Security title and right of possession of the products sold hereunder shall remain with Seller until all payments due from Buyer to Seller (Including deferred payments whether evidenced by notes or otherwise) shall have been made in cash and Buyer agrees to do all acts necessary to perfect and maintain such security right and title in Seller.
19) Cancellations. Buyer may cancel an order only upon written consent and upon payment to Seller of cancellation charges, which shall consider among other things expenses incurred (including but not limited to engineering time) and commitments already made by Seller, and Seller’s profit margin.
(a) The agreement between Buyer and Seller and matter connected with the performance thereof shall be construed in accordance with and governed by the law of the State of Oklahoma, without regard to its conflict of laws principles. The provisions of the United Nations Convention for the International Sale of Goods (“CISG”) shall not govern the rights and obligations of the parties in connection with this order.
(b) Any assignment of the agreement between Buyer and Seller or any rights or obligation of the agreement by Buyer without written consent of Seller shall be void.
(c) Except as may be expressly provided to the contrary in writing, the provisions of the agreement between Buyer and Seller are for the benefit of the parties hereto and not for any other person.
(d) By accepting delivery of any goods sold by Seller, Buyer waives any future claims and rights of setoff or withholding against any payments due hereunder and agrees to pay all sums due regardless of any dispute, setoff, or cross claim.
(e) No waiver by Seller of any breach of any provision of the agreement between Buyer and Seller will constitute a waiver of any other breach.
(f) The terms and conditions set forth above contain all of the representations, stipulations, warranties, agreements and understandings with respect to the subject matter of the agreement between Buyer and Seller, and its execution has not been induced by any representation, stipulation, warranty, agreement or understanding (Including any course of prior dealings between the parties hereto) of any kind other than those set forth herein.
(g) No amendment, addition to, alteration, modification or waiver of all or part of the agreement between Buyer and Seller shall be of any force or effect unless in writing and signed by Seller. If the terms and conditions set forth above conflict with those of any purchase order of Buyer written in connection with the sale of the products or any portion thereof, then the terms set forth above shall govern.
(h) In addition to the rights and remedies conferred upon Seller by law, Seller shall not be required to proceed with the performance of any order or contract, if Buyer is in default in the performance of any order or contract with Seller, and in case of doubt as to Buyer’s financial responsibility, shipments under this order may be suspended or sent sight draft with bill of lading attached by Seller.
(i) No delay or omission by Seller in exercising any right or remedy provided for herein shall constitute a waiver of such right or remedy and shall not be constituted as a bar to or a waiver of any such right or remedy on any future occasion.
21) Entire Contract. The terms and conditions set forth herein constitute the entire expression of all the terms of this agreement and form a complete and exclusive statement as to the agreement between Seller and Buyer notwithstanding any other representations, promises, warranties, statements or agreements to the contrary. Any additional, contradictory or different terms contained in any initial or subsequent order or communication from Buyer pertaining to the products described on the face hereof are hereby objected to. No course of prior dealings between the parties and no usage of trade shall be relevant to supplement or explain any term used in this agreement. Acceptance or acquiescence in a course of performance rendered under this agreement shall not be relevant to determine the meaning of this Agreement even though the accepting or acquiescing party has knowledge of the nature of the performance and the opportunity for objection. No waiver or alteration of terms herein shall be binding unless in writing, signed by an executive officer of Seller.
22) Compliance with Laws. Compliance with Laws. It is the intention of the parties that the transaction covered by these terms and conditions will always, comply with all applicable laws including, without limitation, all export and import laws, regulations and restrictions, foreign corrupt practices and anti-bribery laws.
23) Business Code of Conduct. At Filtration Group, we are committed to creating a better world for our employees, customers, suppliers, investors and community. Buyer hereby acknowledge and agree to abide by the Business Code of Conduct, which is available at www.filtrationgroup.com/en-US/about-us.
24) Export Licensing/ITAR Representation. Buyer agrees to comply with all applicable US and applicable non-US export and import laws and regulations, including but not limited to the International Traffic in Arms Regulation (ITAR) and the Export Administration Regulations (EAR) governing the export of any product and supporting technical data) delivered hereunder. Furthermore, any controlled technical data is not to be placed in the public domain, exported from the US, or given to any Foreign Person in the US without the prior specific written authorization of the Seller and the US Department of State or the US Department of Commerce as applicable. Notwithstanding anything that may be to the contrary Buyer’s obligation as set forth in this provision shall survive the expiration or termination of this agreement. Buyer agrees to defend, indemnify, and hold Seller harmless from all claims or liabilities that may arise from Buyer’s violation of any US or applicable non-US import or export laws.
25) Arbitration. With respect to sales within the United States, any controversy or claim arising out of or relating to the Agreement between Buyer and Seller, or the breach thereof, shall be finally settled in the City and State of the Seller’s accepting offices, by arbitration in accordance with the Rules of the American Arbitration Association, and judgment upon the award rendered by the arbitrator may be entered in any court having jurisdiction thereof. With respect to sales outside the United States, any controversy or claim arising out of or relating to the Agreement between Buyer and Seller, or the breach thereof shall be finally settled in New York, NY under the Rules of Arbitration of the International Chamber of Commerce by one or more arbitrators appointed in accordance with the said Rules and judgment upon the award rendered by the arbitrator may be entered in any court having jurisdiction thereof pursuant to the 1958 Convention on the Recognition and Enforcement of Foreign Arbitral Award.
EO Clause for Purchase Orders, Leases, and Subcontracts
REGULATORY REQUIREMENTS – CITATION REFERENCES
|41 CFR 60-1.4 Equal Opportunity Clause||41 CFR 60-300.10 VETS-4212 Clause|
|41 CFR 60-300.5 Equal Opportunity Clause||29 CFR 471.2 Employee Notice Clause – Appendix A to Subpart A of Part 471|
—Text of Employee Notice Clause
|41 CFR 60.741.5 Equal Opportunity Clause|
“The Equal Employment Opportunity Clause required under Executive Order 11246, and the employee notice clause pertaining to employee rights under the National Labor Relations Act, set forth in 29 CFR Part 471 Appendix A to Subpart A, are incorporated by reference in this purchase order. By accepting this purchase order, vendor additionally certifies that, to the extent applicable, this contractor and subcontractor shall abide by the requirements of 41 CFR §§ 60-1.4(a), 60-300.5(a), 60-300.10 and 60-741.5(a). These regulations prohibit discrimination against qualified individuals based on their status as protected veterans or individuals with disabilities, and prohibit discrimination against all individuals based on their race, color, religion, sex, sexual orientation, gender identity, or national origin. Moreover, these regulations require that covered prime contractors and subcontractors take affirmative action to employ and advance in employment individuals without regard to race, color, religion, sex, sexual orientation, gender identity, national origin, protected veteran status or disability.”, that it complies with the authorities cited above, and that it does not maintain segregated facilities or permit its employees to perform services at locations where segregated facilities are maintained, as required by 41 CFR 60-1.8.”